MMS Construction & Paving v. Head, Inc., et al

by
MMS Construction & Paving, L.L.C. entered into a subcontract with Head, Inc. to pave asphalt runway shoulders at Altus Air Force Base in Oklahoma. The project was delayed and MMS, expressing concern that Head had not been making agreed payments, quit the job. MMS also complained that completing the job would be more expensive than it originally believed because certain requirements were being imposed that Head said would be waived. After MMS quit, Head finished the job, relying on other subcontractors. MMS sued Head on state-law claims of breach of contract, tortious breach of contract, quantum meruit, and misrepresentation, and brought a claim under the federal Miller Act on Head’s surety bond for the project. Head filed a counterclaim, alleging that MMS breached the contract. After a jury trial, MMS was awarded damages and attorney fees. Head filed a motion for judgment as a matter of law or for a new trial, both of which the district court denied. Head appealed, arguing: (1) the evidence at trial was insufficient to show that Head breached the contract; (2) if there was a breach, it was not material; (3) an Oklahoma statute limited MMS’s breach-of-contract damages to the amount unpaid plus interest; (4) the evidence was not sufficient to establish MMS’s alleged lost-profits damages for breach of contract; (5) MMS did not present sufficient evidence to prove misrepresentation or any damages from misrepresentation, MMS waived the misrepresentation claim, and the award of misrepresentation damages duplicated the award of damages for breach of contract; and (6) MMS was not entitled to attorney fees from Head because the Miller Act does not allow recovery of those fees. Upon careful consideration of the district court record, the Tenth Circuit reversed damages award based on the misrepresentation claim because the jury’s award was not supported by any evidence at trial. On all other issues, the Court affirmed. View "MMS Construction & Paving v. Head, Inc., et al" on Justia Law